Skip to Content

Hi-Tech Cabinets & Closets Inc.

STANDARD TERMS AND CONDITIONS OF SALE

Standard Terms and Conditions of Sale

These Standard Terms and Conditions of Sale (“T&C”) apply to all sales of products and services by Hi-Tech Cabinets & Closets Inc. (“Hi-Tech Cabinets & Closets”) within Canada. By placing an order, the client acknowledges and agrees to these T&C.

The client expressly waives reliance on its own terms and conditions. Any variation or modification to these T&C must be agreed to in writing by Hi-Tech Cabinets & Closets.

1. Payment Terms

  • Unless otherwise agreed in writing, invoices are payable as follows:

    1. Upon signing the contract – deposit/payment as specified in the order.

    2. On the first day of delivery of materials.

    3. Upon completion of the work outlined in the contract.

  • Alternate payment timeframes must be expressly stated on the invoice or order confirmation.
  • Payments are to be made in Canadian dollars, free of any set-off, withholding, or deduction.
  • Interest on overdue balances will accrue at 10% per annum or the maximum rate permitted under Alberta law, whichever is lower.
  • Hi-Tech Cabinets & Closets reserves the right to suspend work, delivery, or installation without notice if payment is not received as scheduled.

2. Debt Recovery

  • Accounts unpaid 60 days after the due date may be referred to a licensed Alberta or Canadian debt recovery agency or legal counsel.

  • The client will be responsible for all reasonable costs of collection, including legal fees and disbursements, in accordance with Alberta’s Civil Enforcement Act and related regulations.

3. Taxes and Withholding

  • All applicable federal and provincial sales taxes (GST or Alberta-specific levies, if any) are the responsibility of the client and will be added to the invoice.

  • The client must remit payment in full. No set-off, deduction, or withholding (including foreign tax withholdings) is permitted.

4. Delivery and Installation

  • Delivery dates are estimates only and subject to material availability, labour scheduling, and unforeseen conditions.

  • Hi-Tech Cabinets & Closets will make commercially reasonable efforts to meet timelines but shall not be liable for delays outside its control (e.g., supplier delays, strikes, force majeure, transportation issues).

  • Title to goods passes to the client only upon full payment of the invoice. Risk of loss or damage transfers to the client at delivery/installation.

5. Warranty and Claims

  • Hi-Tech Cabinets & Closets provides a limited warranty in accordance with Canadian consumer protection laws and its published warranty policy.

  • Any claims regarding defects or incomplete services must be made in writing within 8 days of delivery or installation to Hi-Tech Cabinets & Closets’ registered office in Alberta.

  • Claims made after this period will not be accepted.

6. Limitation of Liability

  • Hi-Tech Cabinets & Closets’ liability is limited to the repair, replacement, or refund of the goods or services supplied.

  • Under no circumstances will Hi-Tech Cabinets & Closets be liable for indirect, incidental, or consequential damages, except as required under Canadian federal or Alberta consumer protection legislation.

  • Hi-Tech Cabinets & Closets is not responsible for third-party claims made against the client.

7. Governing Law

  • These T&C shall be governed by the laws of Canada and the laws of the Province of Alberta, without regard to conflict of law provisions.

  • Any disputes shall be heard exclusively in the courts of Calgary, Alberta.